Terms & Conditions

Pryor BATHROOMS

TERMS & CONDITIONS

1. THESE TERMS

1.1 What these terms cover. These are the terms and conditions on which we supply products to you, whether these are Goods or Services.

1.2 Why you should read them. Please read these terms carefully before you sign the acceptance form supplied with your quotation. These terms tell you who we are, how we will provide products to you, how you and we may change or end the contract, what to do if there is a problem and other important information.

2. INFORMATION ABOUT US AND HOW TO CONTACT US

2.1 Who we are. We/us/our (all references relate to) are Pryor Plumbing & Heating Limited trading as Pryor Bathrooms, a company registered in England and Wales. Our company registration number is 06234961 and our registered office is at 41 Worksop Road, Swallownest, Sheffield, S26 4WA.

2.2 How to contact us. You can contact us by telephoning our customer service team at 0114 2878030 or by writing to us at pryorbathrooms@gmail.com.

2.3 How we may contact you. If we have to contact you, we will do so by telephone or by writing to you at the email address or postal address you provided to us in your order.

2.4 ”Writing” includes emails. When we use the words “writing” or “written” in these terms, this includes emails.

3. OUR CONTRACT WITH YOU

3.1 How we will accept your order. Our acceptance of your order will take place when, following your written or verbal acceptance of our quote, we tell you that we are able to provide you with the Goods and/or Services, at which point a contract will come into existence between you and us. Please note that the prices shown on are valid for a period of 28 days from the date of the original quote.

3.2 If we cannot accept your order. If we are unable to accept your order, we will inform you of this and will not charge you for the Goods and/or Services. This might be because products are out of stock, because of unexpected limits on our resources which we could not reasonably plan for or because we have identified an error in the price or description of the product or because we are unable to meet a delivery deadline you have specified.

3.3 Sales literature and website. Any samples, drawings, descriptive matter, or advertising issued by us and any descriptions of the Goods or illustrations or descriptions of the Services contained in our catalogues, brochures or on their website are issued or published for the sole purpose of giving an approximate idea of the Services and/or Goods described in them. They shall not form part of the Contract or have any contractual force.

3.4 Designs and drawings. Any specifications, drawings, dimensions etc., are intended as a guide only. Whilst we take as much care as possible when preparing them, they may include errors and/or inaccuracies and their content is not binding upon us in any way. We reserve the right to withdraw ranges and models that have been replaced by improved or amended designs.

3.5 Your order number. We will assign an order reference to your order and tell you what it is when we accept your order. It will help us if you can tell us the order number whenever you contact us about your order.

3.6 We only sell to the UK. Our brochure and website are solely for the promotion of our products in the UK. Unfortunately, we do not accept orders from or deliver to addresses outside the UK.

4. OUR GOODS

4.1 Goods may vary slightly from their pictures. The images of the products in our brochure or on our website are for illustrative purposes only. Although we have made every effort to display the colours accurately, we cannot guarantee that a device’s display of the colours or the printed pictures in brochures accurately reflect the colour of the products. Your product may vary slightly from those images.

4.2 Goods packaging may vary. The packaging of the product may vary from that shown on images on our website OR in our catalogue or brochure.

4.3 Quality of Goods. We warrant that on delivery, the Goods shall:

(a) conform with their description and any applicable Goods Specification;

(b) be free from material defects in design, material, and workmanship;

(d) have the benefit of the Manufacturer’s Warranty/Guarantee.

4.4 Replacement Goods. Subject to Clause 4.7, we shall, at our option, replace the defective Goods if:

(a) you give notice in writing within 7 days of receipt of the Goods;

(b) we are given a reasonable opportunity of examining such Goods; and

4.5 Warranties and Guarantees. The Goods supplied will come with a Manufacturer’s Warranty or Guarantee (as per Clause 4.3(d)) and the following will apply:

(a) it is your obligation (where applicable) to register the warranty/guarantee with the Manufacturer and in the event of any parts been required to be changed, you will have to contact the manufacturers direct to order any parts unless expressly agreed with us;

(b) the length of the Warranty/Guarantee for the Goods is set by the Manufacturer (not ourselves), and due to this some Goods may have a longer Warranty/Guarantee than others. It is your responsibility to contact the Manufacturers directly, if you want any further details regarding this or in relation to cleaning and care for the Goods.

4.6 Liability for Goods. We shall not be liable for the Goods’ failure to comply with the terms of Clause 4.4 if:

(a) you make any further use of such Goods after giving a notice in accordance with Clause 4.4;

(b) the defect arises because you failed to follow our or the Manufacturers verbal or written instructions as to the use or maintenance of the Goods or (if there are none) good trade practice;

(d) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions; or

(e) the Goods differ from their description as a result of changes made to ensure they comply with applicable statutory or regulatory standards.

4.7 Except as provided in this Clause 4, we shall have no liability to you in respect of the Goods’ failure to comply with the terms set out in Clause 4.3.

4.8 When you become responsible for the Goods. The Goods and materials and their risk will be your responsibility from the time we deliver them to the address you gave us.

4.9 When you own Goods. The title to the Goods and materials shall not pass to you until we have received payment in full (in cash or cleared funds).

4.10 Legal title to the Goods. Until title to the goods has passed to you, (where necessary) you shall:

(a) store the goods separately from all other goods held buy you so that they remain readily identifiable as our property;

(b) not remove, deface, or obscure any identifying mark or packaging on or relating to the Goods;

(c) maintain the Goods in satisfactory condition and keep them insured against all risks for their full price on our behalf from the date of delivery;

(d) give us such information relating to the Goods as we may require from time to time.

4.11 The terms of these Conditions shall apply to any repaired or replacement Goods supplied by us.

4.12 Purchase of Goods only. If you wish to purchase Good only (without installation), the applicable terms of this contract will apply. At point of purchase, we will arrange delivery with you by providing an appropriate date.

5. YOUR RIGHTS TO MAKE CHANGES

5.1 If you wish to make a change to the Goods you have ordered please contact us. We will let you know if the change is possible. If it is possible, we will let you know about any changes to the price of the product, the timing of supply or anything else which would be necessary as a result of your requested change and ask you to confirm whether you wish to go ahead with the change.

6. OUR RIGHTS TO MAKE CHANGES

6.1 Minor changes to the Goods. We reserve the right to change the Goods:

(a) to reflect changes in relevant laws and regulatory requirements; and

(b) to implement minor technical adjustments and improvements.

7. SUPPLY OF GOODS & SERVICES

7.1 These Terms and Conditions apply to the following Goods and Services, provided by the us:

(a) Design and installation of bathrooms;

(b) Sales of Goods.

7.2 Preparing for the works. Because the period taken to install bathrooms vary from house to house, the timescales we provide are a guide only.

7.3 When we will provide the Goods and Services. During the order process we will let you know when we will provide the Goods and Services to you. Please note that we reserve the right to change this date at our discretion and will notify you should this be necessary.

7.4 We are not responsible for delays outside our control. If our supply of the Goods is delayed by an event outside our control, then we will contact you as soon as possible to let you know and we will take steps to minimise the effect of the delay. We will not be liable and direct or indirect loss caused by such delays. Please note It is usual for your appliances, accessories, and worktops to be delivered separately during the period of the installation.

7.5 Labour Guarantee. We will provide a 12-month Labour Guarantee on the installation of the Goods (provided with the Services) commencing from the Service invoice date.

7.6 Works outside of Guarantee period. Any remedial work requested after the expiry of the Labour Guarantee period, including Goods under Warranty/Guarantee will be chargeable at our standard rate, details of which will be provided. Please note that we will be happy to assess and advise on what Goods/parts are required if you are to use another company out of our guarantee period.

7.7 Faults. Please notify us within 24 hours of noticing any faults after completion of our installation. If you fail to do so we will assume that everything is satisfactory to your standard.

8. PROVIDING THE SERVICES

8.1 Prior to commencement. Please make sure that works area is clear. We will not be liable for any damage which may occur due to moving of furniture, fixtures, and fittings.

8.2 Disruption. Fitting a bathroom is a project that will potentially cause disruption and the work can disturb existing pipework. If this should occur, we cannot be held liable for any original pre-existing pipework becoming disturbed when we are required to connect to this original pipework which has not been fitted correctly, in the first instance. Please note our quote is priced and assessed to connect on to your existing system whatever the trade. If something on your existing system fails within the time, we work on your premises we cannot be held liable for incomplete or substandard works carried out by others before us.

8.3 Additional work. Our team is there to carry out the work that’s has been quoted and agreed with you and they are not permitted to carry out any other work on the premises without consent from us. Please also not that if you require any additional Goods or Services in addition to what we originally quoted for, please notify us and we will advise you of the additional fees involved.

8.4 Storage. If we ask you to store any goods or materials whilst the work is ongoing, you are required to oblige and ensure that these are kept in a suitably safe and dry place.

9. YOUR OBLIGATIONS UNDR THE CONTRACT

9.1 Additional Obligations. In addition to any, and all other obligations within this contract, you shall:

(a) ensure that the terms of the order and any information it provides in (in relation to the Goods and Services to be provided) are complete and accurate;

(b) co-operate with us in all matters relating to the Goods and Services;

(c) provide us, our employees, agents, consultants, and subcontractors, with full and clear access to the location where the Goods and Services are to be supplied and other facilities as reasonably required by the us;

(d) provide us with such information and materials as we may reasonably require in order to supply the Goods and Services, and ensure that such information is complete and accurate in all material respects;

(e) obtain and maintain all necessary licences, permissions and consents which may be required for the Goods and Services before the date on which we start;

(f) ensure that the room where the Services are to be provided is cleared;

(g) remove any fixtures and fittings from adjoining walls of rooms where the Goods and Services are to be provided and cover any beds;

(h) provide us with access to utilities at the location;

(i) provide us with parking at the location, within 20 metres of where the Goods and Services are to be supplied;

(j) where applicable, keep all materials, equipment, documents, and other property of ours (Supplier Materials) at your premises in safe custody at its own risk, maintain these Goods and Materials in good condition until returned to us, and not dispose of or use the goods and Materials other than in accordance with our written instructions or authorisation;

(k) comply with all applicable laws, including health and safety laws.

9.2 Customer default. If our performance of any of our obligations under the contract are prevented or delayed by any act or omission by you or your agents, sub-contractors, or employees, or by failure by you to perform any relevant obligation, then:

(a) without limiting or affecting any other right or remedy available to it, we shall have the right to suspend performance of the Services until you remedy the Customer Default, and to rely on the Customer Default to relieve it from the performance of any of its obligations in each case to the extent the Customer Default prevents or delays our performance of any of its obligations;

(b) we shall not be liable for any costs or losses sustained or incurred by you arising directly or indirectly from our failure or delay to perform any of your obligations as set out in this Clause 9.2;

(c) you shall reimburse us on written demand for any costs or losses sustained or incurred by us arising directly or indirectly from the Customer Default.

10. IF THERE IS A PROBLEM WITH THE GOODS OR SERVICES

10.1 How to tell us about problems. If you have any questions or complaints about the goods or services, please contact us. You can telephone our customer service team at 0114 2878030 or write to us at pryorbathrooms@gmail.com.

10.2 Summary of your legal rights. We are under a legal duty to supply goods and materials that are in conformity with this contract. See the box below for a summary of your key legal rights (Consumers only) in relation to this. Nothing in these terms will affect your legal rights.

This is a summary of your key legal rights. These are subject to certain exceptions. For detailed information please visit the Citizens Advice website www.adviceguide.org.uk or call 0808 2231133.

If your product is goods, for example furniture, the Consumer Rights Act 2015 says goods must be as described, fit for purpose and of satisfactory quality. During the expected lifespan of your product your legal rights entitle you to the following:

· up to 30 days: if your goods are faulty, then you can get an immediate refund.

· up to six months: if your goods can’t be repaired or replaced, then you’re entitled to a full refund, in most cases.

If your product is services, for example, the Consumer Rights Act 2015 says:

· you can ask us to repeat or fix a service if it’s not carried out with reasonable care and skill or get some money back if we can’t fix it.

· if you haven’t agreed a price beforehand, what you’re asked to pay must be reasonable.

· if you haven’t agreed a time beforehand, it must be carried out within a reasonable time.

10.3 Your obligation to return rejected goods. If you wish to exercise your legal rights to reject goods you must either return them in person to where you bought them, post them back to us or (if they are not suitable for posting) allow us to collect them from you. We will pay the costs of postage or collection.

11. PRICE AND PAYMENT

11.1 The Price and Payment for goods and services.

(a) the charges shall be calculated on a time and material basis, with specific details stipulated in the quote and payment will be required in accordance with Clause 11.1(b);

(b) the fees for the agreed Goods and Services will be charged in the following manner:

Installation and Supply

(i) Deposit fee – 20% (of total value of the Goods and Materials) required at the point of Order – Please note that this fee is non-refundable in certain circumstances in accordance with Clause 13.1;

(ii) Balance of Goods and Materials – 80% (of total value of the Goods and Materials) on or before the works commencement date;

(iii) Completion – final payment for the cost of labour required upon completion, payable within 7 days of invoice;

(iv) Remaining Goods & Materials - any materials left over once the works are completed, such as pipes, fittings, or tiles will remain our property and we reserve the right to take them back to our store unless expressly agreed with you beforehand or on completion of the works.

Sales only

(v) Payable in full at point of purchase.

11.2 Where to submit payment. You shall pay each invoice submitted by us in full and in cleared funds to a bank account nominated in writing by us, and time for payment shall be of the essence of the Contract.

11.3 VAT. All amounts payable by you under the Contract are inclusive of amounts in respect of value added tax chargeable from time to time (VAT). Please note that prices are subject to change if rates change.

11.4 Debt Recovery and Legal Fees. Under the terms of this agreement, you agree to pay any and all legal costs, fees and disbursements incurred by us instructing Debt Recovery agents of legal representatives to recover outstanding sums owed under the contract from you.

11.5 All amounts due under the Contract shall be paid in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).

12. OUR RESPONSIBILITY FOR LOSS OR DAMAGE SUFFERED BY YOU

12.1 We are responsible to you for foreseeable loss and damage caused by us. If we fail to comply with these terms, we are responsible for loss or damage you suffer that is a foreseeable result of our breaking this contract or our failing to use reasonable care and skill, but we are not responsible for any loss or damage that is not foreseeable. Loss or damage is foreseeable if either it is obvious that it will happen or if, at the time the contract was made, both we and you knew it might happen, for example, if you discussed it with us during the sales process.

12.2 We do not exclude or limit in any way our liability to you where it would be unlawful to do so. This includes liability for death or personal injury caused by our negligence or the negligence of our employees, agents or subcontractors; for fraud or fraudulent misrepresentation; for breach of your legal rights in relation to the products as summarised at Clause 10.2 and for defective products under the Consumer Protection Act 1987.

12.3 When we are liable for damage to your property. If we are providing services in your property, we will make good any damage to your property caused by us while doing so. However, we are not responsible for the cost of repairing any pre-existing faults or damage to your property that we discover while providing the services. This includes any and all pre-existing issues which are discovered after we have removed your old bathroom, which could not previously be seen.

12.4 Further limitations of our potential liability to you. Subject to the terms of Clause 12.2, we shall not be liable to you, whether in contract, tort (including negligence), for breach of statutory duty, or otherwise, arising under or in connection with the Contract for:

(a) loss of profits;

(b) loss of sales or business;

(d) loss of anticipated savings;

(e) loss of use or corruption of software, data, or information;

(f) loss or damage caused by a subcontractor;

(g) any pre-existing damage or wear and tear on you existing fixtures and fittings

(h) any disturbance or issues arising from us connecting to any original (or pre-installed) pipework;

(h) loss of or damage to goodwill; and

(i) any indirect or consequential loss.

12.5 Our total liability. Subject to Clause 12.4 our total liability to you, whether in contract, tort (including negligence), breach of statutory duty or otherwise, arising under or in connection with the Contract, shall be limited to 100% of the total charges paid under the Contract.

12.6 Exclusion. The terms implied by sections 13 to 15 of the Sale of Goods Act 1979 and the terms implied by sections 3 to 5 of the Supply of Goods and Services Act 1982 are, to the fullest extent permitted by law, excluded from the Contract.

12.7 Claims. All claims against us must be brought within one 1 year after the cause of action arises and you agree to waive any statute of limitations which might apply by operation of law or otherwise.

12.8 This Clause 12 shall survive termination of the Contract.

13. ENDING THE CONTRACT

13.1 Your rights to end the contract before works commence. Without affecting any other right or remedy available to it, you may terminate the contract prior to agreed works date by giving us written notice. In such circumstances, we will refund your Deposit fee (Clause 11.1(b)(i)) unless we have already incurred costs on your behalf. Please note that products that are made to order, such as bathroom furniture are non-refundable (and payable in full) or carries a restocking charge.

13.2 Your rights to end the contract after work has commenced. Without affecting any other right or remedy available to it, you may terminate the Contract by providing us immediate written notice if:

(a) we commit a material breach of our obligations under the Contract and (if such breach is remediable) fails to remedy that breach within 72 hours or where replacement Goods and/or Materials items are required to be ordered, then within 6 weeks, after receipt of notice in writing to do so;

(b) we take any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business;

(c) we suspend, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of our business.

13.3 Our rights to end the contract before works commence. Without affecting any other right or remedy available to it, we may terminate the contract prior to agreed works commencing by giving you written notice. Please note that in these circumstances we will refund of the Deposit fee.

13.4 Our rights to end the contract. Without affecting any other right or remedy available to it, we may terminate the Contract with immediate effect by giving you written notice if:

(a) you commit a material breach of any term of the Contract and (if such a breach is remediable) fails to remedy that breach within 24 hours of being notified in writing to do so;

(b) fail to pay any amount due under the Contract on the due date for payment;

(c) you take any step or action in connection with entering bankruptcy, administration, provisional liquidation, bankruptcy or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business;

(d) (where applicable) you suspend, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business;

(e) your financial position deteriorates to such an extent that in our opinion your capability to adequately fulfil your obligations under the Contract has been placed in jeopardy; or

(f) (where applicable) there is a change of control of your business.

13.4 Suspension of services. Without affecting any other right or remedy available to it, we may suspend the supply of Services under the Contract or any other contract between us, if the you fail to pay any amount due under the Contract on the due date for payment, you become subject to any of the events listed in Clause 13.4(c) to Clause 13.4(f), or we reasonably believes that you are about to become subject to any of them.

14. CONSEQUENCES OF ENDING THE CONTRACT

14.1 What happens if the contract is ended early. On ending the Contract:

(a) we may retain the Deposit fee and (where applicable) you will pay any additional sums owed for made to order products, such as bathroom furniture (in accordance with Clause 13.1), plus you shall pay to us all of our outstanding unpaid invoices immediately. In respect of any Goods, Materials and Services supplied but for which no invoice has been submitted, we shall submit an invoice, which shall be payable by you immediately on receipt;

(b) you shall return all of our Goods and Materials which have not been fully paid for. If you fail to do so, then we may enter your premises and take possession of them. Until they have been returned, you shall be solely responsible for their safe keeping and will not use them for any purpose not connected with the Contract.

14.2 Termination or expiry of the Contract shall not affect any rights, remedies, obligations, or liabilities of the parties that have accrued up to the date of termination or expiry, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination or expiry.

14.3 Any provision of the Contract that expressly or by implication is intended to come into or continue in force on or after termination or expiry of the Contract shall remain in full force and effect.

15. DATA PROTECTION & PROCESSING

15.1 We both acknowledge that for the purposes of General Data Protection Regulation (GDPR), that you are the Data Controller, and we are the Data Processor in respect of any Personal Data.

15.2 We shall process the Personal Data only in accordance with your instructions from time to time and shall not process the Personal Data for any purposes other than those expressly authorised by the you.

15.3 We will take all reasonable measures to ensure they adhere to its obligations under Articles 30 and 32 of GDPR taking into account the information that the Data controller has made available to it.

15.4 We shall take reasonable steps to ensure the reliability of all our employees who have access to the Personal Data.

15.5 We both warrant to the other that it will process the Personal Data in compliance with all applicable laws, enactments, regulations, orders, standards, and other similar instruments.

15.6 We warrant that, having regard to the state of technological development and the costs of implementing any measures, we will:

(a) take appropriate technical and organisational measures against the unauthorised or unlawful processing of Personal Data and against the accidental loss or destruction of, or damage to, Personal Data to ensure a level of security appropriate to:

(i) the harm that might result from such unauthorised or unlawful processing or accidental loss, destruction, or damage; and

(ii) the nature of the data to be protected.

(b) take reasonable steps to ensure compliance with those measures.

15.7 We both agree to indemnify and keep indemnified and defend at its own expense the other party against all costs, claims, damages, or expenses incurred by the other party or for which the other party may become liable due to any failure by the first party or its employees or agents to comply with any of its obligations under this Clause 15.

15.8 You acknowledge that we are reliant on you for direction as to the extent to which we are entitled to use and process the Personal Data. Consequently, we will not be liable for any claim brought by a Data Subject arising from any action or omission by us, to the extent that such action or omission resulted directly from your instructions.

15.9 Neither party shall use the other party’s confidential information for any purpose other than to perform its obligations under the Contract.

16. OTHER IMPORTANT TERMS

16.1 Intellectual Property Rights

(a) All Intellectual Property Rights in or arising out of or in connection with the Services (other than Intellectual Property Rights in any materials provided by you) shall be owned by us.

(b) You agree to grant us a fully paid-up, non-exclusive, royalty-free, non-transferable licence to copy and modify any materials provided by you to us for the term of the Contract for the purpose of providing the Services to you.

16.2 Force Majeure. Neither party shall be liable for failure to perform, nor be deemed to be in default, under this Agreement for any delay or failure in performance resulting from causes beyond its reasonable control, including but not limited to acts of God, acts of Governmental authorities, acts of terrorism, natural catastrophe, fire, storm, flood, earthquake, riot, insurrection, civil disturbance, sabotage, embargo, blockade, acts of war, accident, pandemics, epidemics, lightning damage, electromagnetic interference, radio interference, strikes, industrial dispute, power failure or any other cause beyond its reasonable control..

16.3 Assignment and other dealings

(a) We may at any time assign, transfer, subcontract, delegate, or deal in any other manner with any or all of its rights and obligations under the Contract.

(b) You shall not assign, transfer, subcontract, delegate, or deal in any other manner with any of its rights and obligations under the Contract.

16.4 Notices

(a) Any notice or other communication given to a party under or in connection with the Contract shall be in writing and shall be delivered by hand or by pre-paid first-class post or other next working day delivery service at its principal place of business; or sent by email to the address specified in the quote or order.

(b) Any notice or other communication shall be deemed to have been received: if delivered by hand, on signature of a delivery receipt or at the time the notice is left at the proper address; if sent by pre-paid first class post or other next working day delivery service, at 9.00 am on the second Business Day after posting or at the time recorded by the delivery service; or, if sent by fax or email, at 9.00 am on the next Business Day after transmission.

16.5 Severance. If any provision or part-provision of the Contract is or becomes invalid, illegal, or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal, and enforceable. If such modification is not possible, the relevant provision or part-provision shall be deemed deleted. Any modification to or deletion of a provision or part-provision under this clause shall not affect the validity and enforceability of the rest of the Contract.

16.6 Waiver. A waiver of any right or remedy under the Contract or by law is only effective if given in writing and shall not be deemed a waiver of any subsequent breach or default. A failure or delay by a party to exercise any right or remedy provided under the Contract or by law shall not constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict any further exercise of that or any other right or remedy. No single or partial exercise of any right or remedy provided under the Contract or by law shall prevent or restrict the further exercise of that or any other right or remedy.

16.7 No partnership or agency. Nothing in the Contract is intended to, or shall be deemed to, establish any partnership or joint venture between the parties, constitute either party the agent of the other, or authorise either party to make or enter into any commitments for or on behalf of the other party.

16.8 Entire agreement.

(a) The Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations, and understandings between them, whether written or oral, relating to its subject matter.

(b) Each party acknowledges that in entering the Contract it does not rely on and shall have no remedies in respect of any statement, representation, assurance, or warranty (whether made innocently or negligently) that is not set out in the Contract. Each party agrees that it shall have no claim for innocent or negligent misrepresentation [or negligent misrepresentation] based on any statement in the Contract.

16.9 Third parties’ rights. The Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.

16.10 Variation. Except as set out in these Conditions, no variation of the Contract shall be effective unless it is agreed in writing and signed by the parties (or their authorised representatives).

16.11 Governing law. The Contract and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation shall be governed by and construed in accordance with the law of England and Wales.

16.12 Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.